Terms & Conditions

Last updated: March 2026


These Terms and Conditions govern the use of this website and the provision of services by Reddington Construction Services LTD.


By accessing our website or engaging our services, you agree to be bound by these Terms and Conditions.


1. About Us


Reddington Construction Services LTD is a company incorporated in England and Wales (Company Number 16060576).


Registered Office:

Olive Office, The Orchard

Airedale Enterprise Services

Sunderland Street

Keighley

England

BD21 5LE


Phone: 07590916113


We provide construction and related services within the United Kingdom.


2. Use of Our Website


By using this website, you agree:


  • To use it only for lawful purposes
  • Not to misuse, disrupt, or attempt to gain unauthorised access to the website
  • Not to transmit viruses or harmful material
  • Not to copy, reproduce, or exploit website content without written permission


All content on this website, including text, images, logos, and layout, is the property of Reddington Construction Services LTD unless otherwise stated.


We reserve the right to suspend or terminate access to the website if these terms are breached.


3. Quotations and Estimates


Any quotation provided is:

  • Valid for the period stated in the quote
  • Based on the information supplied by the client
  • Subject to site inspection where required


We reserve the right to amend a quotation if additional work, materials, or unforeseen issues arise after inspection or commencement of work.


A contract is only formed once a written acceptance of the quotation is received and confirmed by us.


4. Scope of Work


The scope of work will be detailed in the written quotation or contract.

Any variations or additional work requested by the client may:


  • Require a revised quotation
  • Affect the agreed completion timeframe
  • Incur additional charges


All changes must be agreed in writing before additional work is carried out.


5. Payment Terms


Payment terms will be specified in your quotation or invoice.


We may require:

  • A deposit prior to commencement of work
  • Stage payments for larger projects
  • Full payment upon completion


Failure to make payment within the agreed timeframe may result in:

  • Suspension of work
  • Additional interest or recovery costs where legally permitted


All payments must be made in GBP unless otherwise agreed.


6. Client Responsibilities


The client agrees to:

  • Provide accurate and complete information
  • Ensure access to the property at agreed times
  • Obtain any necessary permissions (unless otherwise agreed)
  • Ensure the site is safe and accessible


We are not responsible for delays caused by restricted access, inaccurate information, or third-party delays outside our control.


7. Completion and Delays


We will use reasonable efforts to complete work within estimated timeframes.


However, we are not liable for delays caused by:

  • Weather conditions
  • Supply chain issues
  • Unforeseen structural problems
  • Regulatory delays
  • Events beyond our reasonable control


Completion dates are estimates unless expressly stated otherwise in writing.


8. Warranties and Liability


We will carry out all work with reasonable skill and care in accordance with UK standards.


To the fullest extent permitted by law:

  • We shall not be liable for indirect or consequential loss
  • Our total liability shall not exceed the total contract value


Nothing in these Terms excludes liability for:

  • Death or personal injury caused by negligence
  • Fraud or fraudulent misrepresentation
  • Any liability that cannot be excluded under UK law


9.Cancellation


Cancellation rights will be provided in accordance with the Consumer Contracts Regulations where applicable.

If you are a consumer and the contract is agreed off-premises or at a distance, you may have a 14-day cooling-off period.

If cancellation occurs after work has commenced, reasonable charges may apply for work already completed and materials ordered.


10. Intellectual Property


All drawings, plans, specifications, and documents prepared by us remain our intellectual property unless otherwise agreed in writing.


They may not be reused, shared, or reproduced without our consent.


11. Data Protection


We process personal data in accordance with our Privacy Policy.


Please refer to our Privacy Policy for full details on how your data is handled.


12. Complaints


If you are dissatisfied with our services, please contact us using the details below. We aim to resolve complaints promptly and professionally.


13. Governing Law


These Terms and Conditions are governed by the laws of England and Wales.


Any disputes shall be subject to the exclusive jurisdiction of the courts of England and Wales.


14. Contact Details


Reddington Construction Services LTD

Olive Office, The Orchard

Airedale Enterprise Services

Sunderland Street

Keighley

England

BD21 5LE


Phone: 07590916113